search
cart
facebook twitter linkedin youtube instagram Spotify Podcasts Apple Podcasts Spotify Podcasts Apple Podcasts
  • Sign In
  • Create Account
  • Sign Out
  • My Account
  • NEWS
  • TOPICS
    • Cool Roofing
    • Event News
    • Latinos in Roofing
    • Low Slope
    • Legal
    • Metal
    • Project Profiles
    • Roofing Supply Pro
    • Roofing Safety
    • Steep Slope
    • Sustainable Roofing
    • Technology
  • EXCLUSIVES
    • Best of Success
    • Contractor Profile
    • IRE Show
    • Roofing Contractor of the Year
      • Enter Roofing Contractor of the Year
    • Top 100
      • Enter the Top 100
    • Young Guns
    • State of the Industry
    • Century Club
  • MULTIMEDIA
    • Videos
    • Podcasts
    • Interactive Spotlights
    • Roofing Quizzes
    • IRE Videos
    • Webinars
    • Photo Galleries
  • PRODUCTS
    • New Products
    • Featured Products
  • COLUMNS
    • Editor's Note
    • Exit Planning
    • Legally Speaking
    • Safety Advice
    • Technical Details
    • Guest Column
  • EVENTS
    • International Roofing Expo
    • Webinars
    • Best of Success Conference
    • Industry Events
  • DIRECTORY
    • Associations
    • Distributors
    • Manufacturer/Supplier
    • Business Services
    • Get Listed
  • MORE
    • Roofing Contractor eNews
    • RC Store
    • Roofing Supply Pro
    • Custom Content & Marketing Services
    • Market Research
    • Sponsor Insights
    • Company Spotlights
    • Classifieds
      • Auctions
      • Business For Sale
      • Business Opportunities
      • Equipment For Sale
      • Positions Available
      • Products
      • Safety
      • Software
      • Services
      • Training
    • Contact Us
  • EMAGAZINE
    • eMagazine
    • Advertise
      • Media Kit
      • Editorial Calendar
      • Contact
    • Archive Issues
  • SIGN UP!
Columns

Legally Speaking: Carefully Review Contract Clauses

March 31, 2003
In this series of articles, we will discuss several of the more common clauses that the roofing contractor will face.

There is a growing trend by general contractors, large and small, to develop terms and conditions for subcontractors to protect themselves from a wide range of liabilities and problems. Generally speaking, most subcontractors either do not read the terms and conditions carefully enough or they do not think that these will actually apply to them when things go wrong. Nothing could be further from the truth. But with a little effort, subcontractors can protect themselves. In this series of articles, we will discuss several of the more common clauses that the roofing contractor will face.

No-Damage-for-Delay Clause

Actually, this clause can be written in many forms, but all forms seek to eliminate financial liability for delays to the project, with wording such as:

“Should Subcontractor be obstructed or delayed in the commencement, prosecution or completion of the Work without fault on its part, and by reason of causes which would entitle the Contractor to an extension of time under the Contract, then Subcontractor shall be entitled to an extension of time only to perform the Work which shall be equal to the extension of time to which the Contractor shall be entitled and granted by the Owner.

“Subcontractor expressly agrees not to make, and hereby waives, any claim for damages, including those resulting from increased labor or material costs, on account of any delay, obstruction or hindrance for any cause whatsoever, whether or not foreseeable and whether or not anticipated, including, but not limited to, causes that would entitle the contractor to an extension of time under the contract, and agrees that the sole right and remedy thereof shall be an extension of time in accordance with the foregoing paragraph.”

While these clauses might be enforceable and a roofer who is delayed on a project might be denied any compensation for this delay, there are some circumstances in which these conditions might not be enforceable.

One possibility is called “active interference.” This approach arises from the notion that every construction contract contains an implied promise not to prevent, hinder, or impede the contractor’s performance.

In the 1996 case of U.S. for Use and Benefit of Evergreen Pipeline Constr. Co., Inc. v Merritt Meridian Constr. Corp., the Second Court invalidated the No-Damage-for-Delay clause because of the general Contractor’s bad faith and malicious conduct. This included failing to honor repeated promises to provide required surveyors; grossly inflating back-charges in an attempt to “break” the subcontractor; backcharging the subcontractor for delays even though the owner had granted a time extension; and failing to make payments to the subcontractor even though the general contractor had been paid.

This generally requires proof of “intentional” and “willful” conduct, but a growing number of courts have found it to exist where the alleged wrongful actions were merely negligent. In fact, several jurisdictions around the country have found that a contractor can argue for the nullification of this clause on grounds of “simple negligence,” which might include: improper sequencing of work; defective plans and specifications; failure to coordinate the work properly; failure to make the work site available; and failure to grant timely extensions.

As a consequence of these developments, many owners and general contractors have modified the No-Damage-for-Delay clause to expressly disclaim owner or contractor negligence. This means that the contractor’s and subcontractor’s sole remedy for delay is the right to seek extensions of time. A failure to request time in accordance with the contract conditions can act as a waiver of the contractor’s right to seek either a time extension or any related damages.

In order for roofing contractors to protect themselves, they should carefully review their subcontract agreement for the No-Damage-for-Delay clause, and strike this clause from the agreement. If this is not possible, the best approach for roofers is to make sure that good field records are kept to show delays and disruption to labor. Also make sure that notices are given for delays, time extensions are requested, any unjustified back-charges are challenged, notices are given for faulty drawings and specifications, and demands are made for proof of any allegation that the roofer is causing delays to the project. These records and the responses from the general contractor might serve as the basis for challenging the No-Damage-for-Delay clause.

Share This Story

Looking for a reprint of this article?
From high-res PDFs to custom plaques, order your copy today!

Recommended Content

JOIN TODAY
to unlock your recommendations.

Already have an account? Sign In

  • Roofing Contractor Group Publisher Jill Bloom

    Physics, the Power of Authenticity and You

    In February's Publisher's Note, Jill Bloom describes a...
    Columns
    By: Jill Bloom
  • The Family Food Fare supermarket in Midland, Mich.

    ‘Rooftop Ninja’ Discovered Living on Roof, Inside Grocery Sign

    A bizarre tale out of Midland, Mich.: a woman dubbed the...
    Roofing News
    By: Bryan Gottlieb
  • A before and after heat measurement comparison

    How Hot is Too Hot in the Attic?

    If the ventilation is working, how hot should the attic...
    Steep Slope Roofing
    By: Paul Scelsi
You must login or register in order to post a comment.

Report Abusive Comment

Subscribe For Free!
  • eMagazine Subscription
  • Sign Up for the eNewsletter
  • Online Registration
  • Manage My Preferences
  • Subscription Customer Service

More Videos

Sponsored Content

Sponsored Content is a special paid section where industry companies provide high quality, objective, non-commercial content around topics of interest to the Roofing Contractor audience. All Sponsored Content is supplied by the advertising company and any opinions expressed in this article are those of the author and not necessarily reflect the views of Roofing Contractor or its parent company, BNP Media. Interested in participating in our Sponsored Content section? Contact your local rep!

close
  • Snow Guard Solutions for Metal Roofs by S-5!
    Sponsored byS-5!

    Safeguard Your Building: How Snow Guards Prevent Costly Roof & Property Damage

  • A hand holding a wooden block that reads 'EVOLVE'
    Sponsored byWatercress Financial

    Embracing Change: A New Era for the Roofing Industry

Popular Stories

QXO closed its acquisition of Beacon Building Supply on April 29, 2025.

QXO Closes Beacon Acquisition, Rebrands Immediately; Jacobs to Ring NYSE Bell

New executive orders signed by President Trump will likely further constrict an already tight labor market for the construction industry.

New Executive Orders Will Further Squeeze Labor Force

President Trump’s trade war is causing real harm to the construction sector, including roofing contractors.

Trade War Fallout: Contractors Are Delaying Projects and Cutting Crews

Roofing Contractor Webinar

Events

May 22, 2025

Remote Teams 101: The New Way to Hire

Our industry experts will guide you through what remote hiring and outsourcing should look like, how it can help you grow, and why it’s easier (and less scary) than you might think. If you want to save time, find great talent, and grow your business, this is one session you don’t want to miss!

December 3, 2025

The Premier Roofing Conference: Best of Success

Join roofing professionals from across the nation at the 2025 Best of Success conference, the ultimate destination for roofing professionals seeking the latest industry insights and networking opportunities. Pick up strategies for critical challenges like workforce shortage with innovative solutions, explore the latest advancements in roofing technology and sustainable practices, and gain valuable insights from industry leaders on navigating the evolving roofing landscape.

View All Submit An Event

Related Articles

  • Legally Speaking: Construction Contracts - The Waiver of Owner Notice Provisions

    See More
  • Legally Speaking: Liquidated Damages Provisions in Construction Contracts

    See More
  • Legally Speaking: “Design Delegation” — Beware!

    See More
×

Be in the forefront of the roofing industry!

Join thousands of professionals today. Shouldn’t you know what they know?

JOIN NOW!
  • RESOURCES
    • Advertise
    • Contact Us
    • Directories
    • Store
    • Want More
  • SIGN UP TODAY
    • Create Account
    • eMagazine
    • eNewsletter
    • Customer Service
    • Manage Preferences
  • SERVICES
    • Marketing Services
    • Reprints
    • Market Research
    • List Rental
    • Survey/Respondent Access
  • STAY CONNECTED
    • LinkedIn
    • Facebook
    • Instagram
    • YouTube
    • X
  • PRIVACY
    • PRIVACY POLICY
    • TERMS & CONDITIONS
    • DO NOT SELL MY PERSONAL INFORMATION
    • PRIVACY REQUEST
    • ACCESSIBILITY

Copyright ©2025. All Rights Reserved BNP Media.

Design, CMS, Hosting & Web Development :: ePublishing